Justia North Dakota Supreme Court Opinion Summaries

In Spring 2008, Williams Company Construction, Inc. entered into a construction contract to remodel the Friendly Smiles Cosmetic Dentistry Office owned by Dr. Brenda Barfield. Dr. Barfield previously leased the building from Williams Company owner Glen Williams for approximately five years before she purchased the property from him in 2008. Dr. Barfield hired Williams to remodel the building because of its construction experience and familiarity and knowledge of the building. When Dr. Barfield hired Williams, she did not know whether the remodeling work would be done by Williams or subcontractors. Dr. Barfield did not deal directly with any subcontractors during the remodeling project nor did she direct Williams to hire any specific subcontractors. During the remodel, Williams served as the general contractor and hired subcontractors to do various construction tasks. In December 2008, a section of a copper water pipe froze and burst. The frozen water pipe caused minor water damage and was repaired by plumbing subcontractor Home Heating. During the repair process, a Home Heating employee cut a hole in the wall to locate the leak and discovered that the air in the plumbing wall was cold. The employee was concerned the pipe could freeze again and notified the Friendly Smiles Cosmetic Dentistry Office about the cold air. Dr. Barfield contacted Williams to express her concern about the pipes re-freezing from the cold air. According to testimony, Williams told Dr. Barfield not to worry about the pipes freezing again because of circulating warm air around the hole. Dr. Barfield also wanted the hole in the wall patched, but had difficulty in securing Williams or Home Heating to fix it. Dr. Barfield made repeated requests for Williams or Home Heating to resolve the cold air issue, but they did not fix the problem. Approximately one week after the pipe was fixed, the water pipe froze and broke again, this time causing extensive water damage to the dental office. Dr. Barfield and her insurance company, Travelers Insurance, brought suit against Williams, Home Heating (and other subcontractors) for negligence, and breach of contract. Before trial, the parties stipulated that the total amount of damages was $220,046.09. Williams requested the trial court to include a jury instruction concerning the independent contractor distinction (C-55.25), and a jury instruction pertaining to the failure of a party to produce witnesses (C-80.30). The court denied the two requests. At the pretrial hearing, the parties stipulated that the case would be tried before the jury based on comparative fault. The jury was given a special verdict form and found Williams seventy percent at fault, Home Heating twenty-five percent at fault, and Dr. Barfield five percent at fault. Judgment was entered against Williams. Williams subsequently filed a motion for a new trial arguing the court erred in denying its requested jury instructions and there was insufficient evidence for the jury to find Williams seventy percent at fault for the damages. Following a hearing, the district court denied the motion. Williams appealed the district court's judgment, but finding no reversible error, the Supreme Court affirmed. View "Travelers Cas. Ins. Co. of America v. Williams Co. Construction" on Justia Law

American General Contractors, Inc. ("AGC"), appealed a judgment assessing liability and awarding damages and interest for the cost of delays in the construction of the Williams County Law Enforcement Center in Williston. C&C Plumbing and Heating, LLP ("C&C"), the successful bidder for the mechanical prime contract, filed suit when construction the center was delayed approximately two years after "substantial completion" was supposed to have happened. The district court concluded it was appropriate for the County and AGC to share responsibility for providing temporary shelter and heat on the project. The court apportioned 47 percent of the liability for the costs of the delay for the three and one-half months of active interference to the County and 53 percent to AGC, for the four months delay inherent to the industry. The court awarded C&C approximately $73,000 on its claim against the County. After offsetting amounts owed between the parties, the court awarded AGC approximately $424,000 on its claim against the County. The court awarded Davis Masonry approximately $96,000 from AGC for masonry work completed under its subcontract with AGC, and rejected AGC's claimed offsets to that amount. Davis had provided heat, cover and shelter for the project during cold weather and sought $649,000 from the County and AGC for that expense including prompt payment interest. Davis had settled with the County for $530,000, and the court ruled AGC was responsible for 53 percent of the remaining $119,000, or $63,070. AGC argues the district court erred in determining AGC was liable for any of the costs incurred from the delay under its contract with the County. Finding no reversible error, the Supreme Court affirmed the district court. View "C&C Plumbing and Heating, LLP v. Williams County" on Justia Law

Patrick Wagner appealed the grant of summary judgment that held as a matter of law that his property was burdened by either an express or an implied roadway easement, and that dismissed his claims for injunctive relief and damages against Crossland Construction Company, Inc., Baker Hughes Oilfield Operations, Inc., M & K Hotshot & Trucking, Inc., and Titan Specialties, Ltd. Upon review of the matter, the Supreme Court concluded that, as a matter of law, the language in the warranty deed at issue in this case did not create or reserve an express easement. Furthermore, the Court concluded genuine issues of material fact precluded the district court from resolving whether an implied easement exists. Accordingly, the Court reversed and remanded the case for further proceedings. View "Wagner v. Crossland Construction Company, Inc." on Justia Law

Plaintiffs-Appellants Terence and Rachel Barrett appealed the dismissal of their claims against Defendant-Appellee Harry Gilbertson (dba Harry Gilbertson Construction) in a contract dispute. Plaintiffs argued that the trial court erred in dismissing their breach of contract claims related to the construction of their house, and that the court abused its discretion in denying their motion for attorney's fees. Upon review of the trial court record, the Supreme Court concluded that Plaintiffs failed to establish Defendant breached the terms of the construction contract or that the trial court did abused its discretion in denying the Plaintiffs' claim for attorney's fees. View "Barrett v. Gilbertson" on Justia Law

Kadrmas, Lee & Jackson, Inc., ("KLJ") appealed a district court judgment awarding the City of Valley City ("City") costs and expenses the City incurred defending itself in the underlying lawsuit and pursuing its indemnity claim against KLJ. The City entered into a contract with KLJ to provide engineering services for a paving and sewer project. The City hired a general contractor for the project. The contract between the City and the contractor required the contractor to furnish all labor, materials, and equipment for the project. The contractor was required to provide a payment bond under the terms of its contract with the City, and St. Paul Fire & Marine Insurance Company ("St. Paul") was the surety under the bond. Specialized Contracting, Inc. ("SCI"), entered into a subcontract with the contractor to complete some of the work on the project. In 2007, SCI sued St. Paul for breach of its duties under the payment bond, seeking compensation for additional work SCI alleged it completed on the project for which the contractor refused to pay. St. Paul served a third-party complaint against the City for breach of contract and indemnity, alleging the concrete repair work was outside the scope of the City's contract with the contractor, the City was liable to the contractor for any additional compensation SCI was claiming against the payment bond if SCI established KLJ's decision to replace the concrete was beyond the scope of the contract, and the City was required to indemnify St. Paul for any judgments against it in favor of SCI arising from decisions made by KLJ. Upon review of the matter, the Supreme Court concluded KLJ did not have a duty to defend the City. The Court reversed the district court's judgment awarding the City costs and expenses, and remanded the case for a determination of whether KLJ was entitled to recover its costs and expenses as a prevailing party. View "Specialized Contracting, Inc. v. St. Paul Fire & Marine Ins." on Justia Law

Sisters of Mary of the Presentation Long Term Care, d/b/a Ave Maria Village ("Sisters of Mary"), appealed, and Northern Excavating Co., Inc. ("Northern") cross-appealed a trial court's judgment awarding Northern $81,694.23 plus interest at 1.5 percent and costs at $743.33, and awarding Sisters of Mary $3,231.00 in attorney's fees. In October of 2009, Sisters of Mary and Northern executed a contract wherein Northern agreed to repair a water main break on Sisters of Mary's property for the cost of its "[t]ime and [m]aterials[.]" The contract did not contain a specific price. Following completion of the repairs, Northern submitted a bill for $103,244.11 to Sisters of Mary. Sisters of Mary found the bill excessive and refused to pay, asserting the repairs only had a value of approximately $40,000. Northern filed a construction lien covering the repaired property and sued Sisters of Mary seeking $98,806.98 for breach of contract and foreclosure of the lien. Sisters of Mary answered and counterclaimed alleging breach of contract, unlawful sales practices, and invalid construction lien/slander of title. Sisters of Mary also sought a jury trial. By stipulation, issues relating to the foreclosure of the construction lien were reserved and not submitted to the jury. The jury returned a verdict awarding Northern $81,694.23 plus interest at 1.5 percent for time and materials provided under the contract. After the verdict was rendered, Sisters of Mary applied for its costs and attorney's fees. In its post-trial brief, Sisters of Mary claimed it successfully challenged Northern's lien and argued the court was required to award it all of its attorney's fees and costs associated with the action. In its own post-trial brief, Northern argued it was unreasonable to require lienholders to pay costs and attorney's fees when a lienholder does not recover the precise amount claimed in a lien. The trial court ultimately awarded Sisters of Mary a portion of its attorney's fees, explaining it was a reasonable award given Sisters of Mary failed to specify "any fees that were directly related to the construction lien issue[.]" The trial court also found Northern was the prevailing party and awarded its costs. Upon review, the Supreme Court concluded the Legislature intended to award an owner literally all of the costs and attorney's fees arising out of a lawsuit when challenging a lien was not the only disputed cause of action: "[t]here is nothing in the statute or the legislative history to support that conclusion. We recognize that Sisters of Mary must provide the court with an itemization of its attorney's fees and costs in order for the trial court to determine those related to the successful contest of the accuracy of the lien." The Court reversed the award of attorney's fees and costs and remanded that issue to the trial court. Because the district court misconstrued the fees and costs statute, the Court reversed in part and remanded for the district court to determine the reasonable amount of attorney's fees associated with contesting the accuracy of the construction lien. View "Northern Excavating v. Sisters of Mary of the Presentation" on Justia Law

K & L Homes appealed a district court judgment based upon a jury verdict in favor of Neal Leno and Susan Leno ("the Lenos"). On appeal, K & L Homes argued: (1) the district court erred by deciding K & L Homes had not sufficiently raised the defense of fault by the Lenos in its answer; (2) the court erred by refusing to instruct the jury on comparative fault, the court erred by denying K & L Homes' request for inspection and not allowing a defendant to testify on his observations during a jury viewing; and (3) the court erred by ruling K & L Homes had not disclaimed any implied warranties as a matter of law. The Lenos purchased a newly-constructed house from K & L Homes. The Lenos alleged they noticed cracks, unevenness, and shifting due to improper construction not long after purchasing the house from K & L Homes. Initially, the Lenos claimed K & L Homes was negligent, breached the parties' contract, and breached implied warranties. The Lenos claimed the parties' contract implied warranties that the house would be built according to the applicable codes, that it would fit its purpose as a residence, and that it would be constructed according to engineering standards and in a workmanlike condition. K & L Homes requested the jury be instructed on comparative fault, but the district court denied the proposed comparative fault instruction. The district court decided K & L Homes had not adequately pled fault, and comparative fault did not apply to Lenos' cause of action. The district court also found, as a matter of law, that K & L Homes had not disclaimed any implied warranties in a Homeowners' Guide given to the Lenos at the closing on the house. Upon review, the Supreme Court agreed with the findings made by the district court and affirmed its decisions as to all issues raised on appeal. View "Leno v. K & L Homes" on Justia Law

Plaintiffs-Appellants Doug Zink and Ted Keller appealed a district court judgment that dismissed their complaint, denied their motions, and awarded Enzminger Steel attorney's fees and costs. Enzminger Steel contracted with Doug Zink to supply components for a new grain drying site. The contract listed Zink as the purchaser, but Zink and his son Jeremy signed the contract. Doug Zink and Keller contend that they had formed a partnership for the purposes of constructing and operating the site. They further alleged that it was this partnership and not the Zinks separately, that entered into the contract with Enzminger Steel. Sometime after construction began, Zink and Keller learned that certain unsuitable components had been used in the site's construction. Zink and Keller refused to make payments under the contract. Two separate breach of contract actions followed, one brought by Enzminger Steel and one brought by Zink and Keller. At trial, the district court repeatedly questioned whether the alleged partnership between Zink and Keller was a ruse to allow Keller to practice law without a license. Keller later told the court that he and Zink had entered into an unwritten partnership agreement to share profits and losses. The court replied, "[T]he agreement that you are in is to share profits off this lawsuit which is not allowed." Neither Zink nor Keller produced any documents to prove the partnership. The district court entered an order denying all of the motions in this case and dismissed the action brought by Zink and Keller with prejudice. On appeal, Zink and Keller argued that the district court abused its discretion by denying the various motions in this case, ordering them to prove that a partnership existed, and awarding attorney's fees and costs to Enzminger Steel. Upon review, the Supreme Court found that while the district court had the power to dismiss a case in the absence of a party's motion, it must provide the parties with adequate notice and an opportunity to respond. Because Doug Zink did not have adequate notice or an opportunity to respond, the dismissal of his case with prejudice was reversed. The Court remanded the case for further proceedings.

Duane Peterson, Mid Am Group, LLC, and Mid Am Group Realty (collectively âMid Amâ), Village Homes at Harwood Groves, LLC (Village Homes), and First International Bank and Trust (First International) all had a stake in the insurance proceeds from a 2007 hail storm that damaged their respective properties. The trial court granted summary judgment to Village Homesâ Homeownersâ Association that represented ten property owners of the Village Homes community impacted by the storm. Mid Am developed and built the insured properties, but Mid Am had only sold ten of fifty units. When the hail storm hit, Mid Am submitted a proof of loss with its insurance company for the residences it still owned. First American was in the process of foreclosing on those unsold Mid Am properties. The insurance check was sent to Mid Am, but First American sued to get possession of the proceeds, and the individual owners were permitted to intervene. The court took control of the proceeds, and held that neither Mid Am nor First International were entitled to them. The court ruled that Mid Am, as fiduciary to the ten owners, should distribute the proceeds among them. Mid Am appealed, arguing that the ownersâ association did not have standing to intervene in the suit for the proceeds. The Supreme Court concluded that the ownersâ association had standing to intervene, and that it was not an error of the trial court to allow the owners to make their claim for the proceeds. The Court affirmed the grant of summary judgment.